Terms of Service

1. Introduction

Welcome to Bela Modular Homes ("we," "our," or "us"). These Terms of Service ("Terms") govern your use of our website, services, and products. By accessing or using our services, you agree to be bound by these Terms.

2. Definitions

For the purposes of these Terms:

• "Services" means all services provided by Bela Modular Homes including modular home design, construction, and related services
• "Website" means the Bela Modular Homes website located at belamodularhomes.com
• "User" or "You" means the individual or entity accessing or using our Services
• "Content" means all materials, information, and data available on our Website

3. Use of Services

You agree to use our Services only for lawful purposes and in accordance with these Terms. You are responsible for:

• Providing accurate and complete information
• Maintaining the confidentiality of your account credentials
• Complying with all applicable laws and regulations
• Using the Services in a manner that does not harm our systems or other users

4. User Obligations

By using our Services, you agree to:

• Provide accurate project requirements and specifications
• Cooperate with our design and construction process
• Make timely payments for services rendered
• Comply with local building codes and regulations
• Respect intellectual property rights

5. Intellectual Property

All content, designs, plans, and materials provided by Bela Modular Homes are protected by intellectual property laws. You may not:

• Copy, reproduce, or distribute our designs without permission
• Use our trademarks or branding without authorization
• Reverse engineer our proprietary systems
• Create derivative works without explicit consent

6. Pricing and Payment

All pricing is subject to change without notice. Payment terms include:

• Initial deposit required to begin project work
• Progress payments based on project milestones
• Final payment due upon project completion
• Late payment fees may apply
• All taxes and duties are additional

7. Project Timeline and Delivery

We strive to complete projects within agreed timelines, however:

• Timelines are estimates and may vary based on circumstances
• Delays caused by client changes may affect delivery dates
• Weather conditions may impact construction schedules
• We are not liable for delays beyond our reasonable control

8. Limitation of Liability

To the maximum extent permitted by law, Bela Modular Homes shall not be liable for:

• Indirect, incidental, or consequential damages
• Loss of profits, data, or business opportunities
• Delays in project completion due to unforeseen circumstances
• Third-party actions or natural disasters

9. Termination

Either party may terminate services with written notice. Upon termination:

• All outstanding payments become immediately due
• Work in progress may be subject to additional charges
• Client retains rights to completed work
• Confidential information remains protected

10. Governing Law

These Terms shall be governed by and construed in accordance with the laws of Nepal. Any disputes shall be resolved through the courts of Kathmandu Valley.

11. Contact Information

For questions about these Terms, please contact us: